Loading...
86-R-48RESOLUTION NO. 86-R-48 A RESOLUTION OF THE CITY COUNCIL OF THE CITY OF EDGEWATER, FLORIDA, AUTHORIZING THE APPROPRIATE OFFICIALS OF THE CITY OF EDGEWATER TO EXECUTE AN AGREEMENT FOR PROFESSIONAL SERVICES WITH GERKEN, UPHAM, SMITH, ARCHITECTS AND CONSULTANTS, INC.; REPEALING ALL RESOLUTIONS IN CONFLICT HEREWITH, AND PROVIDING FOR AN EFFECTIVE DATE. WHEREAS, the City Council of the City of Edgewater, Florida, at a special meeting held September 29, 1986, selected the firm of Gerken, Upham, Smith, Architects and Consultants, Inc., to provide the architectural services to design the new 10,000 square foot Library building. NOW, THEREFORE, BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF EDGEWATER, FLORIDA: SECTION 1: That the City Council of the City of Edgewater, Florida, authorizes the appropriate officials of the City of Edgewater to execute an agreement for professional services with Gerken, Upham, Smith, Architects and Consultants, Inc. SECTION 2: A copy of said Agreement is attached to this Resolution and by reference incorporated herein. SECTION 3: That all resolutions or parts of resolutions in conflict herewith be and the same are hereby repealed. SECTION 4: That this Resolution shall take effect immediately upon its adoption by the City Council of the City of Edgewater, Florida, at a regular meeting of said Council held on the 20th day of October ,198 6 , and approved as provided by law. This Resolution was introduced and sponsored by Councilman Astinz and was read and passed by a vote of the City Council of the City of Edgewater, Florida, at a regular meeting of said Council held on the 20th day of October , 198 6 , and authenticated as provided by law. ROLL CALL VOTE AS FOLLOWS: �th Q. CITY CLERK Authenticated this 2 day of October ,198 6 . YOR -2- Res. No. 86-R-48 THE AMERICAN INSTITUTE OF ARCHITECTS fey: Fd� AIA Document 9141 Standard Form of Agreement Between Owner and Architect Tt11S D( , AN ATTORNEY AGREEMENT 1977 EDITION HAS IMPORTANT LEGAL CONSEQUENCES; CONSULTATION WFTH <n F, AGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION made as of the Twenty Seventh, day of October in the year of Nineteen Hundred and Eighty -Six BETWEEN the Owner: City of Edgewater, Florida P.O. Box 100 t Edgewater, Florida 32032 and the Architect: Gerken, Upham, Smith, Architects and Consultants, Inc. P.O. Box 155 Ormond Beach, Florida 32075 For the following Project: (Include detailed description of Project location and scope.) For the design of a 10,000 s.f. Library for the City of Edgewater, including but not limited to: Stack and Reading Area; Circulation Desk; Staff/Workroom; Offices; Shipping/Receiving/Storage; Multi —Purpose Space and Toilets and provision for expansion. The Owner and the Architect agree as set forth below. Gorr^Enl fln,',UA, Ivi. 1951. 1"], ffie, feet. '%3. 1Y6. 1961, 1WU, 1971. N tvn At, The nmen<an manure m A,rhn< u. 1715 : w Armn M ,k uw. wnninRlnn. O.C. Note, Ren,^du< of lee male<L1 he Tin e< ,nMlanlul ern 1of �t rn —1houl petwoo-n of the MA —Wes the mpvnhhl law, of the Un,IN Sines and w11 N auM1le t ^ Le ,Icon. AIA DOCUMENT 5161 • 0W (Et ARCHI TICE ACHE MINT IIIRIEENTN EDITION • IULV 1W7 • AIA6 • 0Im 0/41-1f77 I THE AMERICAN INSTITUTE Of ARCHITECTS, tAS NEW VORa AVENUE, N.W., WASHINCTON, D.C. 300i C TERMS AND CONDITIONS OF AGREEMENT BETWEEN OWNER AND ARCHITECT ARTICLE 1 ARCHITECT'S SERVICES AND RESPONSIBILITIES BASIC SERVICES The Architect's Basic Services consist of the five phases described in Paragraphs 1.1 through 1.5 and include normal structural, mechanical and electrical engineering services and any other services included in Article 15 as part of Basic Services. 1.1 SCHEMATIC DESIGN PHASE 1.1.1 The Architect shall review the program furnished by the Owner to ascertain the requirements of the Project and shall review the understanding of such requirements with the Owner. 1.12 The Architect shall provide a preliminary evalua- tion of the program and the Project budget requirements. each in terms of the other, subject to the limitations set forth in Subparagraph 3.2.1. 1.1.3 The Architect shall review with the Owne• alterna- tive approaches to design and construction of the Project. 1.1.4 Based on the mutually agreed upon program and Project budget requirements, the Architect shall prepare, for approval by the Owner, Schematic Design Documents consisting of drawings and other documents illustrating the scale and relationship of Project components. 1.1.5 The Architect shall submit to the Owner a State- ment of Probable Construction Cost based on current area, volume or other unit costs. 1.2 DESIGN DEVELOPMENT PHASE 1.2.1 Based on the approved Schematic Design Docu- ments and any adjustments authorized by the Owner in the program or Project budget, the Architect Shall pre- pare, for approval try the Owner, Design Development Documents consisting of drawings and other documents to fix .and describe the size and character of The entire Project as to architectural, stroclural, mechanical and elec. trical systems, materials and such other elements as may be appropriate. 1.2.2 The Architect shall submit to the Owner a further Statement of Probable Construction Cost. 1.3 CONSTRUCTION DOCUMENTS PHASE 1.3.1 Based on the approved Design Development Doc- uments and any further adjustments in the scope or qual- ity of the Project or in the Project budget authorized by the Owner, the Architect shall prepare, for approval by the Owner, Construction Documents consisting of Draw- ings and Specifications setting forth in detail the require- ments for the construction of the Project. 1.3.2 The Architect shall assist the Owner in the prepara- tion of the necessary bidding information, bidding forms, the Conditions of the Contract, and the form of Agree- ment between the Owner and the Contractor. 1.3.3 The Architect shall advise the Owner of any adjust- ments to previous Statements of Probable Construction Cost indicated by changes in requirements or general market conditions. 1.3.4 The Architect shall assist the Owner in connection with The Owner's responsibility for filing documents re- quired for the approval of governmental authorities hav- ing jurisdiction over the Project. 1.4 BIDDING OR NEGOTIATION PHASE 1.4.1 The Architect, following the Owners approval of the Construction Documents and of the latest Statement of Probable Construction Cost, shall assist the Owner in obtaining bids or negotiated proposals, and assist in awarding and preparing contracts for construction. 1.5 CONSTRUCTION PHASE —ADMINISTRATION OF THE CONSTRUCTION CONTRACT 15.1 The Construction Phase will commence with the award of the Contract for Construction and, together with the Architect's obligation to provide Basic Services under this Agreement, will Terminate when final payment to the Contractor is due, or in the absence of a final Certificate for Payment or of such due date, sixty days after the Dale of Substantial Completion of the Work, whichever occurs first. 1.5.2 Unless otherwise provided in this Agreement and incorporated in the Contract Documents, the Architect shall provide administration of the Contract for Construc- tion as set forth below and in the edition of AIA Docu- ment A201, General Conditions of the Contract for Con- struction, current as of the date of this Agreement. 1.5.3 The Architect shall be a representative of the Owner during the Construction Phase, and shall advise and consult with the Owner. Instructions to the Contrac- tor shall he forwarded through the Architect. The Archi- lect shall hive ,wthnrily III eel nit behalf of the Owner only to the extent provided in the Contract Documents Unless otherwise modified by written instrument in ac- cordance with Subparagraph 1.5.16. 1.5.4 The Architect shall visit the site at intervals ap- propriate to the stage of construction or as otherwise agreed by the Architect in writing to become generally familiar with The progress and quality of the Work and to determine in general if the Work is proceeding in accord- ance with the Contract Documents. However, the Archi- tect shall not be required to make exhaustive or con- tinuous on -site inspections to check the quality or quan- tity of the Work. On the basis of such on -site observa- tions as an architect, the Architect shall keep the Owner informed of the progress and quality of the Work, and shall endeavor to guard the Owner against defects and deficiencies in the Work of the Contractor. 1.53 The Architect shall not have control or charge of and shall not be responsible for construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, for the acts or omissions of the Contractor, Sub- AIA DOCUMENT 8141 • OWNERARCHITECT AOREEWNT I THIRTEENTH EDITION I IUEY 1W I AIM • 019)) THE AMERICAN INSTITUTE q ARCHITECTS. 1,15 4EW YORK AVENUE, HIN, WASHINCTON, D.C. 20.OE 314149" 3 O J contractors or any other persons performing any of the Work, or for the failure of any of them to carry out the "Irk in accordance with the Contract Documents. 1.5 : T %e Architect shall at all times have access to the Wort, ,.. =ver it is in preparation or progress. 1.a.Y T. - vrchitece st I determine the amounts owing to the Cors.rbr based :. • observations at the site and on evaluations othe CoettraCor's Applications for Payment, and shall $sus 'ertificates 'ar P:+mer :., such amounts, as provided in ,ae Contras. Dot,: ,ents. 1.5.8 The issuance of a Certi-. ate for Payment shall constitute a representation by the Am- te<, to the Owner, based on the Architect's observations at the site as pro- vided in Subparagraph 1.5.4 and on the data comprising the Contractor's Application for Payment, that the Work has progressed to the point indicated; that, to the best of the Architect's knowledge, information and belief, the qual- ity of the Work is in accordance with the Contract Docu. ments (subject to an evaluation of the Work for con- formance with the Contract Documents upon Substantial Completion, to the results of any subsequent tests re- quired by or performed under the Contract Documents, to minor deviations from the Contract Documents cor- rectable prior to completion, and to any specific qualifica- tions stated in the Certificate for Payment); and that the Contractor is entitled to payment in the amount certified. However, the issuance of a Certificate for Payment shall not be a representation that the Architect has made any examination to ascertain how and for what purpose the Contractor has used the moneys paid on account of the Contract Sum. 1.5.9 The Architect shall be the interpreter of the re- quirements of the Contract Documents and the judge of the performance thereunder by both the Owner and Contractor. The Architect shall render interpretations nec- essary for the proper execution or progress of the Work with reasonable promptness on written request of either the Owner or the Contractor, and shall render written de. cision%. within a reasonable time, on all claims, disputes and Other matters in question between the Owner and the Contractor rel-1+ng to the execution or progress of the Wirk or the interpretation of the Contract Documents. 1 1'10 -' prelat u.-a a: � recisions of the Architect shall be c_with Iht FEE,, of -nd reasonably inferable from I'z Cortnct Doct ie^lsand shall he in written or graphic form. in the capacity of 'men eter and judge, the Architect shall endeavor to recur., lilhful perform- ance by both the Owrar and the Cnntractor, shall not show partiality to either, and shall n, t he liable (or the result of any interpretation or decision rendered in good faith in such capacity. 1.5.11 The Architect's decisions in matters relating to artistic effect shall be final if consistent with the intent of the Contract Documents. The Architect's decisions on any other claims, disputes or other matters, including those in question between the Owner and the Contractor, shall be subject to arbitration as provided in this Agree- ment and in the Contract Documents, 1.5.12 The Architect shall have authority to reject Work which does not conform to the Contract Documents. Whenever, in the Architect's reasonable opinion, it is necessary or advisable for the implementation of the Intent of the Contract Documents, the Architect will have author- ity to require special inspection or testing of the Work in accordance with the provisions of the Contract Docu- ments, whether or not such Work be then fabricated, in- stalled or completed. 15.13 The Architect shall review and approve or take other appropriate action upon the Contractor's submittals such as Shop Drawings, Product Data and Samples, but only for conformance with the design concept of the Work and with the information given in the Contract Documents. Such action shall be taken with reasonable promptness so as to cause no delay. The Architect's ap- proval of a specific item shall not indicate approval of an assembly of which the item is a component. 1.5.14 The Architect shall prepare Change Orders for the Owner's approval and execution in accordance with the Contract Documents, and shall have authority to order minor changes in the Work not involving an adjustment in the Contrarl Sum or an extension of the Contract Time which arc not inconsistent with the intent of the Contract Documents. 1.5.15 The Architect shall conduct inspections to deter- mine the Dales of Substantial Completion and final com- pletion, shall receive and forward to the Owner for the Owners review written warranties and related documents required by the Contract Documents and assembled by the Contractor, and shall issue a final Certificate for Pay- ment. 1.5.16 The extent of the duties, responsibilities and lim- itations of authority of the Architect as the Owner's rep- resentative during construction shall not be modified or extended without written consent of the Owner, the Con. tractor and the Architect. 1.6 PROIECT REPRESENTATION BEYOND BASIC SERVICES 1.6.1 If the Owner and Architect agree that more ex- tensive representation at the site than is described in Paragraph 1.5 shall be provided, the Architect shall pro- vide one or more Project Representatives to assist the Architect in carrying out such responsibilities at the site. 1.6.2 Such Project Representative% hall be selected, em. ployed and directed by the Architect, and the Architect shall be compensated Therefor as mutually agreed be- tween the Owner and the Architect as set forth in an ex- hibit appended to this Agreement, which shall describe the duties, responsibilities and limitations of authority of such Project Representatives. 1.6.3 Through the observations by such Project Repre- sentatives, the Architect shall endeavor to provide further protection for the Owner against defects and deficiencies in the Work, but the furnishing of such project representa. tion shall not modify the rights, responsibilities or obliga- tions of the Architect as described in Paragraph 1.5. 1.7 ADDITIONAL SERVICES the following Services are not included In Basic Services unless so identified in Article 15. They shall be provided if authorized or confirmed in writing by the Owner, and they shall be paid for by the Owner as provided in this Agreement, in addition to the compensation for Basic Services. 4 B141.1977 MA DOCUMENT RNl . OWNER -ARCHITECT AGREEMENT. THIRTEENTH EDITION . IULT MA . M.N. 0ISO THE AMERICAN INSTITUTE Of ARCHITICTs, 1735 NEW TORx AVENUE, N,W., WAWINGEGN, D.C. amE 1.7.1 Pro; 1oi; : Tall -Es of the Owner's needs, and pro- gramming ie req s re -:ants .; the Project. 1.71 Provding firan -.l fi-sbi•ror other special studies 1.7.3 Poviding planning .urvirs, site eraluatio-,, envi- ronmental studies or comparable stcd.n of ^ -.:pective sites, and preparing spcial surveys; swdie, :ad submis- sions required for approvals of go.enlmantal authorities or others having jurisdiction over the Project 1.7.4 Providing services relative to future facilities, sys- tems and equipment which are not intended to be con- structed during the Construction Phase. 1.7.5 Providing services to investigate existing conditions or facilities or to make measured drawings thereof, or to verify the accuracy of drawings or other information fur- nished by the Owner. 1.7.6 Preparing documents of alternate, separate or sequential bids or providing extra services in connection with bidding, negotiation or construction prior to the completion of the Construction Documents Phase, when requested by the Owner. 1.7.7 Providing coordination of Work performed by separate contractors or by the Owner's own forces. 1.7.8 Providing services in connection with the Work of a construction manager or separate consultants retained by the Owner. 1.7.9 Providing Detailed Estimates of Construction Cost, analyses of owning and operating costs, or detailed quan- tity surveys or inventories of material, equipment and labor. 1.7.:4 eroviding interior design and other similar ser- vices Ieq,: d for or in connection with the selection, procuren I .r Installation of furniture, furnishings and related equip ln.t. 1.7.1', Provichr; SE,ces f planning tenant or rental spaces. 1.7.12 Making mvis,ons io D.-wings, Specifications Or other documents when such mLsions are ..,consistent with v-ripen 'aperovals o• Irstruc.ons pre,iooJy given, are required by the enactm-nt or mvbion cl codes, laws or regulations subsequent to the preparatic of such doc- uments or are due to other causes not solely within the control of the Architect. 1.7.13 Preparing Drawings, Specifications and supporting data and providing other services in connection with Change Orders to the extent that the adjustment in the Basic Compensation resulting from the adjusted Con- struction Cost is not commensurate with the services re- quired of the Architect, provided such Change Orders are required by causes not solely within the control of the Architect. 1.7.14 Making investigations, surveys, valuations, inven- tories or detailed appraisals of existing facilities, and serv- ices required in connection with construction performed by the Owner. 1.7.15 Providing consultation concerning replacement of any Work damaged by fire or other cause during con- struction, and furnishing services as may be required In connection with the replacement of such Work. 1.7.16 Providing services made necessary by the default of the Contractor, or by major defects or deficiencies in the Work of the Contractor, or by failure of performance of either the Owner or Contractor under the Contract for Construction. 1.7.17 Preparing a set of reproducible record drawings showing significant changes in the Work made during construction based on marked -up prints, drawings and other data furnished by the Contractor to the Architect. 1.7.16 Providing extensive assistance in the utilization of any equipment or system such as initial start-up or testing, adjusting and balancing, preparation of operation and maintenance manuals, training personnel for operation and maintenance, and consultation during operation. 1.7.19 Providing services after issuance to the Owner of the final Certificate for Payment, or in the absence of a final Certificate for Payment, more than sixty days after the Date of Substantial Completion of the Work 1.7.20 Preparing to serve or serving as an expert witness in connection with any public hearing, arbitration pro- seeding or legal proceeding. 1.7.21 Providing services of consultants for other than the normal architectural, structural, mechanical and elec- trical engineering services for the Project. 1.7.32 Providing any other services not otherwise in- cluded in this Agreement or not customarily furnished in accordance with generally accepted architectural practice. 1.8 TIME 1.8.1 The Architect shall perform Basic and Additional Services as expeditiously as is consistent with professional skill and care and the orderly progress of the Work. Upon request of the Owner, the Architect shall submit for the Owner's approval a schedule for the performance of the Architect's services which shall be adjusted as required as the Project proceeds, and shall include allowances for peri- ods of time required for the Owner's review and approval of submissions and for approvals of authorities having jurisdiction over the Project. This schedule, when approved by the Owner, shall not, except for reasonable cause, be exceeded by the Architect. ARTICLE 2 THE OWNER'S RESPONSIBILITIES 2.1 The Owner shall provide full information regarding requirements for the Project including a program, which shall set forth the Owner's design objectives, constraints and criteria, including space requirements and relation- ships, flexibility and expandability, special equipment and systems and site requirements. 2.2 If the Owner provides a budget for the Project it shall include contingencies for bidding, changes in the Work during construction, and other costs which are the responsibility of the Owner, including those described in this Article 2 and in Subparagraph 3.1.2. The Owner shall, at the request of the Architect, provide a statement of funds available for the Project, and their source. ALA DOCUMENT 1141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • IUEY 1ST/ - AIM • m 19" THE AMERICAN INSTITUTE W ARCHITECTS, 93S NEW YORK AVENUE, N.W., WASHINGTON. O.C. MOSS 5141-1977 5 ram, 2.3 The Owner shall designate, when necessary, a rep- resentative authorized to act in the Owner's behalf with respectto the Project. The Owner or such authorized representative shall examine the documents submitted by the Architect and shall render decisions pertaining thereto Promptly, to avoid unreasonable delay in the progress of the Architect's services. 2.4 The Owner shall furnish a legal description and a certified land survey of the site, giving, as applicable, grades and lines of streets, alleys, pavements and adjoin- ing property; righlsof-way, restrictions, easements, en- croachments, zoning, deed restrictions, boundaries and contours of the site; locations, dimensions and complete data pertaining to existing buildings, other improvements and trees; and full information concerning available serv- ice and utility lines both public and private, above and below grade, including inverts and depths. 2S The Owner shall furnish the services of soil engi- neers or other consultants when such services are deemed necessary by the Architect. Such services shall include test borings, test pits, soil bearing values, percolation tests, air and water pollution tests, ground corrosion and resistivity tests, including necessary operations for determining sub- soil, air and water conditions, with reports and appropri- ate professional recommendations. 2.6 The Owner shall furnish structural, mechanical, chemical and other laboratory tests, inspections and re- ports as required b- I iw or the Contract Documents. 2.7 The Owner shalt r•m sr all legal, accounting and in- sura-•e rounseli;.3 set;. -es . nay be necessary at any time L- he Pro;-ct, in, ,dir:q ,,ch a,.diting services as the Ow - -r ma-, rcr ;-e to Yens, . e Cortrac'ar's Applica- tions to naymznt „- to asLerta,r how or for what pur- poses t`c Conlrario. uses Th.! n< Teys pad by or on be- half o' !%e Owner. 2.0 The services, information, surveys and reports re- quired by Paragraphs 2.4 through 2.7 inclusive shall be furnished at the Owner's expense, and the Architect shall be entitled to rely upon the accuracy and completeness thereof. 2.9 If the Owner observes or otherwise becomes aware of any fault or defect in the Project or nonconformance With the Contract Documents, prompt written notice thereof shall be given by the Owner to the Architect. 2.10 The Owner shall furnish required information and services and shall render approvals and decisions as ex. peditiously as necessary for the orderly progress of the Architect's services and of the Work. ARTICLE 3 CONSTRUCTION COST 3.1 DEFINITION 3.1.1 The Construction Cost shall be the total cost or estimated cost to the Owner of all elements of the Project designed or specified by the Architect. 3.1.2 The Construction Cost shall include at current market rates, including a reasonable allowance for over- head and profit, the cost of labor and materials furnished by the Owner and any equipment which has been de - signed, specified, selected or specially provided for by the Architect. 3.1.3 Construction Cost does not include the compen- sation of the Architect and the Architect's consultants, the cost of the land, rights -of -way, or other costs which are the responsibility of the Owner as provided in Arti- cle 2. 3.2 RESPONSIBILITY FOR CONSTRUCTION COST 3.2.1 Evaluations of the Owner's Project budget, State. ments of Probable Construction Cost and Detailed Estimates of Construction Cost, if any, prepared by the Architect, represent the Architect's best judgment as a design professional familiar with the construction indus- try. It is recognized, however, that neither the Architect nor the Owner has control over the cost of labor, mate- rials or equipment, over the Contractor's methods of de- termining bid prices, or over competitive bidding, market or negotiating conditions. Accordingly, the Architect cannot and does not warrant or represent that bids or negotiated prices will not vary from the Project budget proposed, established or approved by the Owner, if any, or from any Statement of Probable Construction Cost or other cost estimate or evaluation prepared by the Archi- tect. 3.2.2 No fixed limit of Construction Cost shall be estab- lished as a condition of This Agreement by the furnishing, proposal or establishment of a Project budget under Sub- paragraph 1.1.2 or Paragraph 2.2 or otherwise, unless such fixed limit has been agreed upon in writing and signed by the parties hereto. If such a fixed limit has been estab- lished, the Architect shall be permitted to include con. tingencies for design, bidding and price escalation, to de. termine what materials, equipment, component systems and types of construction are to be included in the Con. tract Documents, to make reasonable adjustments in the %cope of The Project and to include in the Contract Docu- ments alternate bids to adjust the Construction Cost to the fixed limit. Any such fixed limit shall be increased in the amount of any increase in the Contract Sum occurring after execution of the Contract for Construction. 3.2.3 If the Bidding or Negotiation Phase has not com- menced within Three months after the Architect submits the Construction Documents to the Owner, any Project budget or fixed limit of Construction Cost shall be ad- justed to reflect any change in the general level of prices in the construction industry between the date of submis. sion of the Construction Documents to the Owner and the date on which proposals arc sought. 3.2.4 If a Project budget or fixed limit of Construction Cost (adjusted as provided in Subparagraph 3.2.3) is ex- ceeded by the lowest bona fide bid or negotiated pro- posal, the Owner shall (1) give written approval of an increase in such fixed limit, (2) authorize rebidding or re- negotiating of the Project within a reasonable time, (3) if the Project is abandoned, terminate in accordance with Paragraph 10.2. or (4) cooperate in revising the Project scope and quality as required to reduce the Construction Cost. In the case of (4), provided a fixed limit of Construc- tion Cost has been established as a condition of this Agree- ment, the Architect, without additional charge, shall mod- ify the Drawings and Specifications as necessary to comply 6 5141-1977 AIA DOCUMENT oral • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • IULY IV7 • AIA4 4 01Sn THE AMERICAN INSTITUTE Of ARCHITECTS, DSS NEW YORx AVENUE. N.W., WASHINGTON, D.C. Iaa'IE i 0 with the fixed limit. The providing of such service shall be the limit of the Architect's responsibility arising from the establishment of such fixed limit, and having done so, the Architect shall be entitled to compensation for all services performed, in accordance with this Agreement, whether or not the Construction Phase is commenced. ARTICLE 4 DIRECT PERSONNEL EXPENSE 4.1 Direct Personnel Expense is defined as the direct sal- aries of all the Architect's personnel engaged on the Proj- ect, and the portion of the cost of their mandatory and customary contributions and benefits related thereto, such as employment taxes and other statutory employee bene- fits, insurance, sick leave, holidays, vacations, pensions and similar contributions and benefits. ARTICLE 5 REIMBURSABLE EXPENSES 5.1 Reimbursable Expenses are in addition to the Com- pensation for Basic and Additional Services and include actual expenditures made by the Architect and the Archi- tects employees and consultants in the interest of the Project fo- the expenses listed in the following Sub- paragraphs: 5.1.1 Expense - transportation in connection with the Project; liv 1g ex:eoses in connection with out-of-town travel; long dista.ce communicstior:r and fees paid for securing approval of authorities mvi. g risdiction over the Project. 5.1.2 Experse of reproductions, pcdage r ' andling of Drawings, Specifications and other docume--s, excluding reproductions for the office use of the Architect and the Architect's consultants. 5.1.3 Expense of data processing and photographic pro- duction techniques when used in connection with Addi- tional Services. 5.1.4 If authorized in advance by the Owner, expense of overtime work requiring higher than regular rates. 5.1.5 Expense of renderings, models and mock-ups re- quested by the Owner. 5.1.6 Expense of any additional insurance coverage or limits, including professional liability insurance, requested by the Owner in excess of that normally carried by the Architect and the Architect's consultants. ARTICLE 6 PAYMENTS TO THE ARCHITECT 6.1 PAYMENTS ON ACCOUNT OF BASIC SERVICES 6.1.1 An initial payment as Set forth in Paragraph 14.1 is the minimum payment under this Agreement. 6.1.2 Subsequent payments for Basic Services shall be made monthly and shall be in proportion to services per- formed within each Phase of services, on the basis set forth in Article 14. 6.1.3 If and to the extent that the Contract Time initially established in the Contract for Construction is exceeded or extended through no fault of the Architect, compensa- tion for any 3asic Services required for such extended period of Administration of the Construction Contract shall be computed as set forth in Paragraph 14.4 for Addi- tional Services. 6.1.4 When compensation is based on a percentage of Construction Cost, and any portions of the Project are deleted or otherwise not constructed, compensation (or such portions of the Project shall be payable to the extent services are performed on such portions, in accordance with the schedule set forth in Subparagraph 14.2.2, based on (t) the lowest bona fide bid or negotiated proposal or, (2) if no such bid or proposal is received, the most recent Statement of Probable Construction Cost or Detailed Esti. mate of Construction Cost for such portions of the, Project. 6.2 PAYMENTS ON ACCOUNT OF ADDITIONAL SERVICES 6.2.1 Payments on account of the Architect's Additional Services as defined in Paragraph 1.7 and for Reimbursable Expenses as defined in Article S shall be made monthly upon presentation of the Architect's statement of services rendered or expenses incurred. 6.3 PAYMENTS WITHHELD 6.3.1 No deductions shall be made from the Architect's compensation on account of penalty, liquidated damages or other sums withheld from payments to contractors, or on account of the cost of changes in the Work other than those for which ahe Architect is held legally liable. 6.4 PROJECT SUSPENSION OR TERMINATION 6.4.1 If the Project is suspended or abandoned in whole or in part for more than three months, the Architect shall be compensated for all Services performed prior to receipt of written notice from the Owner of such suspension or abandonment, together with Reimbursable Expenses then due and all Termination Expenses as defined in Paragraph 10.4. If the Project is resumed after being suspended for more than three months, the Architect's compensation shall be equitably adjusted. ARTICLE 7 ARCHITECT'S ACCOUNTING RECORDS 7.1 Records of Reimbursable Expenses and expenses per- taining to Additional Services and Services performed on the basis of a Multiple of Direct Personnel Expense shall be kept on the basis of generally accepted accounting principles and shall be available to the Owner or the Owner's authorized representative at mutually Convenient times. ARTICLE 8 OWNERSHIP AND USE OF DOCUMENTS 8.1 Drawings and Specifications as instruments of serv- ice are and shall remain the property of the Architect whether the Project for which they are made is executed or not. The Owner shall be permitted to retain copies, in- cluding reproducible copies, of Drawings and Specifica- tions for information and reference in connection with the Owner's use and occupancy of the Project. The Drawings and Specifications shall not be used by the Owner on ALA DOCUMENT 9141 • C WHER-ARCHITECT AGREEMENT • THIRTEENTH EDITION • IULY 11" • AUR • 01E77 THE AMERICAN INSTITUTE OF ARCHITECTS, Ins NEW YORE AVENUE. N.W.. WASHINGTON, D.C. ]WOE 914149" 7 other projects, for additions to this Project, or for comple- tion of this Project by others provided the Architect is not in default under this Agreement, except by agreement in writing and with appropriate compensation to the Archi- tect. 8.2 Submission or distribution to meet official regulatory requirements or for other purposes in connection with the Project is not to be construed as publication in derogation of the Architect's rights. ARTICLE 9 ARBITRATION 9.1 All claims, disputes and other matters in question between the parties to this Agreement, arising out of or relat!rg to this Agreement or the breach thereof, shall be decided , arbitration in accordance with the Construc. tion Ineuv! Arbitration Rules of the American Arbitra- tion ASK-iat w 'hen obtaining unless the parties mutu. ally agree .then se. No arbitration, arising out of or re- lating to t}:sJ.g, -ement, s lj include, by consolidation, joinde• v- it.. acy w)ar many er a,., •''ditional person not a Party to tr s . ere-ment a ept by wr:^=n consent con- taining a sp•— fic _ierence t-,'hs A;re±:zit and signed by the A.6.tect, t, a Owner, z.. J ary Orr 11 : mor.;ought to be j6.1' :. Any « "sent to arhit-atimW. ir.+ :ving an ad- ditiona person or persons shall not cer;titute consent to arbitration of any dispute not described therein or with any person not named or described therein. This Agree- ment to arbitrate and any agreezzrt to arbitrate with an additional person or persons do!y consented to by the parties to this Agreement shall be specifically enforceable unde• the prevailing arbitration law. 9.2 NoYce of the demand for arbitration shall be filed in writing with the other party to this Agreement and with the American Arbitration Association. The demand shall be made within a reasonable time after the claim, dispute or other matter in question has arisen. In no event shall the demand for arbitration be made after the date when institution of legal or equitable proceedings based on such claim, dispute or other matter in question Would be barred by the applicable statute of limitations. 9.3 The award rendered by the arbitrators shall be final, and judgment may be entered upon it in accordance with applicable law in any court having jurisdiction thereof. ARTICLE 10 TERMINATION OF AGREEMENT 10.1 This Agreement may be terminated by either party upon seven days' written notice should the other part fail substantially to perform in accordance with its terms ,..,,;ugh n� fault of the party initiating the termination. 10.2 T his Agreement may be terminated by the Owner upon it'easr sever. Jays' written notice to the Architect in the evert that the Protect is permanently abandoned. 10.3 In the event of termination not the fault of the Ar- chitect, the Architect shall be comoensated for all services Performed to termination date, tit-,'ther ,..6 Reimburs- able Expenses then due srd at' T^minq—;7 • Ze: rases as defined in Para,gaph 10.4. 10.4 Termination Expenses include expenses directly at- Iributable to termination for which the Architect is not otherwise compensated, plus an amount computed as a percentage of the total Basic and Additional Compensa- tion earned to the time of termination, as follows .1 20 percent if termination occurs during the Sche- matic Design Phase; or .2 10 percent if termination occurs during the Design Development Phase; or .3 5 percent if termination occurs during anT subse- quent phase. ARTICLE 11 - MISCELLANEOUS PROVISIONS ' 11.1 Unless otherwise specified, this Agreement shall be governed by the law of the principal place of business of the Architect. 11.2 Terms in this Agreement shall have the same mean- ing as those in AIA Document A201, General Conditions of the Contract for Construction, current as of the date of this Agreement. 11.3 As between the parties to this Agreement: as to all acts or failures to act by either party to this Agreement, any applicable statute of limitations shall commence to run and any alleged cause of action shall be deemed to have accrued in any and all events not later than the refe- vant Date of Substantial Completion of the Work, and as to any acts or failures to act occurring after the. relevant Date of Substantial Completion, not later than the date of issuance of the final Certificate for Payment. 11.4 The Owner and the Architect waive all rights against each other and against the contractors, consult- ants, agents and employees of the other for damages cov- ered by any property insurance during construction as set forth in the edition of AIA Document A201, General Con- ditions, current as of the date of this Agreement. The Owner and the Architect each shall require appropriate similar waivers from their contractors, consultants and agents. ARTICLE 12 SUCCESSORS AND ASSIGNS 12.1 The Owner and the Architect, respectively, bind themselves, their partners, successors, assigns and legal representatives to the other party to this Agreement and to the partners, successors, assigns and legal representa- tives of such other party with respect to all covenants of this Agreement. Neither the Owner nor the Architect shall assign, sublet or transfer any interest in this Agreement without the written consent of the other. ARTICLE 13 EXTENT OF AGREEMENT 13.1 This Agreement represents the entire and integrated agreement between the Owner and the Architect and supersedes all prior negotiations, representations or agree- ments, either written or oral. This Agreement may be amended only by written instrument signed by both Owner and Architect, 8 9141-19" AIA W '.MENf MO • OWNERIcHITE[T AG0.FFMFNT • iH10.tFENtH [OITION • It1tV 11" •AIM • 0190 THE 9NgIUN INSTITUTE Or A0.CNITECra, 173S NEW Y00.x AV[NU[, NM. WA9HINGTON, O.C. IDnlf r ARTICLE 14 BASIS OF COMPENSATION The Owner shall compensate the Architect for the Scope of Services provided, in accordance with Article 6, Payments to the Architect, and the other Terms and Conditions of this Agreement, as follows: 14.1 AN INITIAL PAYMENT of Two Thousand, Five Hundred and no/100--- dolfars($2,500.00) shall be made upon execution of this Agreement and credited to the Owner's account as follows: To the first payment. 14.2 c IC COMPENSATION I 14.2.1 FC7 BASIC:SERVICES, a. cEscribed in Paragraphs 1.1 through 1.5, and any other services included in Article 15 as .art of Basic Ser ces, B.;ic Compensation shall be computed as follows: Ptr a in•ea ban 91 C'.Me r- -1 .n., a n. � :-ams, muhipl' w MCI -I -I . aM idemiry Mae' m .Akh IN ... svi r "Rod, el compema- nm, awh. it rNr'ury.l Compensation shall be a fixed fee of Thirty—five Thousand and 00/100 Dollars ($35,000.00). 14.2.2 Where compensation is based on a Stipulated Sum or Percentage of Construction Cost, payments for Basic Services shall be made as provided in Subparagraph 6.1.2, so that Basic Compensation for each Phase shall equal the following percentages of the total Basic Compensation payable: nwlW NIr aadnional Maus a appr "" ) Schematic Design Phase: $ 5,530.00 percent ( 16 %) Design Development Phase: $ 6.300.00 percent( 18 %) Consu.ctl,, uments Phase: $15,105.00 percent( 43%1 eliding or Nagoti_' — Phase: $ 1,665.00 percent ( 5 %1 Construction Ph„se: $ 6,400.00 percent ( 18 %) 14.3 FOR PROJECT REPRESENTATION BEYOND BASIC SERVICES, as described in Paragraph 1.6, Compensation shall be computed separately in accordance with Subparagraph 1.6.2. AIA DOCUMENT 810 1 OWNER -ARCHITECT AGREEMENT , THIRTEENTH EDITION . IUEV 1977 1 MAR 1 O IM eulagn 9 THE AMERICAN INSTITUTE OE AaCNITECTS, 1731 NEW WRC AVENUE. N.W., WASHINGTON. O.C. laOaE 14.4 COMPENSATION FOR ADDITIONAL SERVICES 14.4.1 FOR ADDITIONAL SERVICES OF THE ARCHITECT, as described in Paragraph 1.7, and any other services in- cluded in Article 15 as part of Additional Services, but excluding Additional Services of consultants, Compen- sation shall be computed as follows: 11" nl Anil nl ,iw,ww lion,'aIwhi. rnr+ arrdlm iwwa'l I Obrrl eennnnrl &,prune lm Prin rvIc and rmPlr7wr+ amt Mmlii, I+inn h d , .. , 1,mh we , it rMuirM. Idm1AY +,ws,hr srrvina In whin Mr rrukr m lhMh n/ mmlmnulinn a", ll nrmnary.I ri-.'pals tim at the fixed rate of Seventy-five and 00/100 Dollars ($75.00) pzr rcur:.. Techracciaras ._ve true iixt:d rate of Thirty-five and 001100 Dollars ($35.00) yea hour. Clerical time at the fixed rate of Thirty and 00/100 Dollars ($30.00) per hour. 14.4.2 FOR ADDITIONAL SERVICES OF CONSULTANTS, including additional structural, mechanical and electrical engineering services and those provided under Subparagraph 1.7.21 or'd tified in Article 15 as part of Addi- tional Services, a multiple of one and three -tenths I i NT I times the amounts billed to the Architect for such services. fldenlirp IMrilk IwHf of mmulNnv . Mid, 15, 1,nMmd1 14.5 FOR REIMBURSABLE EXPENSES, as described in Article 5, and any other item included in Article 15 as Reim- bursable Expenses, a multiple of one and three -tenths I 1 I times the amounts ex. pended by the Architect, the Architect's employees and consultants in the interest of the Project. 14.6 Payments ch E the Architect and unpaid under this Agreement shall bear interest from the date payment is due at the r, : ent<-cd below, or in the absence thereof, at the legal rate prevailing at the principal place of business of the Ar- Aect INmr arrl Aw, role of i,,rc s. aa,,M upon. W .At the rate if One and one 'half (1.5) percent per month after thirty (30) days. M R vwh M1 _ k I T+. Mrw E Act. ­,I,,abtr and Inral , —tin, urd l I- and mhrr aulalnma al IN, O and A b I f , coMJ el . I Am ,. F 1 ( I IM1 ^ nlm Intl rlaMhrr, m r alleU IF, valldit, M Ihw prwi srsN.Nr I"a N-.Imuld M h d with r rn, a de4 + ,gdilicalion. n, nlYrr rM,nrrmrnu awA Ia nnm n div1--1 nr wa.wr al 14.7 The Owner and the Architect agree in accordance w:th the Terms and Conditions of this Agreement that: 14.7.1 IF THE SCOPE of the Project or of the Architect's Services is changed materially, the amounts of compensation shall be equitably adjusted. 14.7.2 IF THE SERVICES covered by this Agreement have not been completed within twenty-four (24) months of the date hereof, through no fault of the Architect, the amounts of compensation, rates and multiples set forth herein shall be equitably adjusted. 10 8141-1477 AIA DOCUMENr 1141 OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • IUIY 1• AIAR a 01977 THE AMERICAN INSTITUTE OF ARCHITECTS. Ins NEW YORK AVENUE. N.W.. WASHINGTON. D.C. axon ARTICLE 15 OTHER CONDITIONS OR SERVICES 15.1 .he Own_r will. provide all engineering services for Civil/Stormwater requiree :oi _he es::a ` _Auding paving, water and sewer utilities to within five feet `.s ) of the building. 15.2 The Architect will provide all other basic services including normal engineering services for Heating, Ventilating and Air Conditioning; Plumbing; Electrical; Structural and Landscaping. AIA DOCUMENT I'M • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • IULY IM • AM4 • p 19" THE AMERICAN INRITUTE Of ARCHITECTS. 1115 NEW YORR AVENUE, NW, WASHINGTON, OC. 1fM R711.1f77 11 This Agreement entered into as of the day and year first written above. OWNER CITY OF EDGEWATER, FLORIDA ARCHITECT CERKEN, UPHAM, SMITH BY Cornelia Martinez City Clerk/Administrator d Finance Director ARCHITECTS AND CONSULTANTS, INC. BY CdbL arl-Gerken, AIA President T= 1141-1977 A:A DOCUgCNT btl • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • IUIY 19A • AIM • 0IM THE M11R'CAN INSTITUTE Of ARCHITECTS, 1731 NEW YORK AVENUE, N.W, WASHINGTON, D.C. aII'IE